Type : Tender ( IFB )

Category : Engineering & Construction , Specialized Construction
Ref No : KMTC/7/2014-2015
Closing : Fri, Mar 06, 2015 10:00
Eligibility :  Kenya




TENDER NO. KMTC/7/2014-2015

The Kenya Medical Training College invites interested and competent bidders for the above works. Bids that meet the criteria below as a minimum will be considered for evaluation.

Proof of work of similar magnitude and complexity undertaken in the last five years.
The bid bond of 2% tender sum, must be in form of a bank guarantee from a reputable bank or approved insurance company.
Adequate equipment and key trained personnel for the types of works.   Attach CVs of key personnel.
Sound financial standing. Attach audited accounts for the last three years and adequate access to bank credit lines.
Litigation history declaration of the company (both court and arbitration cases).
Duly signed and stamped standard forms.
Tax compliance certificate.
Incorporation/Registration certificate.
Current registration with the National Construction Authority, category NC3 and above for building works.
Employment of specialist subcontractors. Attach registration certificate of electrical and plumbing installation subcontractors. These should be registered under category NC 4 and above.
Further, the following tender shall be treated as non-responsive and therefore subject to disqualification:

A tender from a tenderer whose ongoing project(s) is/are behind schedule and without approval for extension of time.
A tender from a tenderer who has been served with a default notice on ongoing project(s) or whose contract in a Government project has been terminated in the past.
Preference will be given to a responsive tenderer who has evidence of undertaking related works in the past five years.

Interested and eligible bidder may inspect and obtain tender documents from the KMTC Administration Block, 1st floor Procurement department upon payment of non refundable fee of Kshs.1,000 per document through a bankers cheque payable to Director, KMTC Nairobi, or deposited at National Bank of Kenya KMTC A/C No. 01003058521700.

Sealed tenders accompanied by duly completed forms and security bonds as specified in the tender documents, in plain envelopes indicating the Tender Number and Tender Name without identifying the bidder and addressed to:

The Director

Kenya Medical Training College

P.O. Box 30195-00100


Should be deposited in the tender box situated at the entrance of the KMTC Hqrs administration block on or before 6th March 2015 at 10.00 A.M. Bids will be opened immediately thereafter at the Milne Hall in the presence of bidders or their representatives who choose to attend.

Head – Supply Chain Manager

For: Director

Leave a Reply