Kenya Industrial Estates Limited tender

Last Updated 14 years ago by Kenya Engineer

KENYA INDUSTRIAL ESTATES LIMITED Tender: PROPOSED CONSTRUCTION OF INDUSTRIAL SHEDS – NAIROBI Closing Date: 28/09/2012            
KENYA INDUSTRIAL ESTATES LIMITED
TENDER INVITATION NOTICE
The Kenya Industrial Estates Limited invites tenders from contractors to  carry out the following works.

No;1   
Tender No:KIE/04/2012-2013   
Description:Proposed construction of industrial sheds – NAIROBI    
COntractors in Category: C and above    
Tender fee:5, 000/   
Closing dates:28/09/2012

No:2   
Tender No:KIE/05/2012-2013   
Description:Proposed construction of industrial sheds – BOMET    
Contractors in Category :E and  D    
Tender fee:5, 000/-   
Closing dates:24/09/2012

No:3   
Tender Number:KIE/06/2012-2013   
Description:Proposed construction of industrial sheds – SAGANA    
Contractors in cartegory:E and D    
Tender fee:5, 000/-   
Closing dates:24/09/2012

No:4   
Tender Number:KIE/07/2012-2013   
Description:Proposed construction of industrial sheds – MACHAKOS    
Contractors in Category:E and D    
Tender fee:5, 000/-   
Closing date:24/09/2012

No:5   
Tender Number:KIE/08/2012-2013   
Description:Proposed construction of industrial sheds – KWALE    
Contractors in Category:E and D    
Tender fee:5, 000/-   
Closing dates:24/09/2012

No:6   
Tender Number:KIE/09/2012-2013   
description:Proposed construction of industrial sheds – MERU   
Contractors Category:E and D    
Tender fee:5, 000/-   
Closing dates:24/09/2012
 
Interested contractors who appear in the current building contractors Register (proof of Registration) may obtain tender documents form the Procurement Unit office Kenya Industrial Estates Limited Headquarters, 3rd floor Room 315, Likoni /Lusingeti road junction, Industrial Area, P. O. Box 78029 – 00507 NAIROBI) on Mondays to Friday with exceptions  of public holidays or downloaded form the website (www.kie.co.ke) upon payment of tender fee before submission of the tender documents.
 
Interested bidders should know that only those meeting the criteria below as a minimum supported by relevant documents at submission will be considered for further evaluation:-
1.       Prof of similar magnitude and complexity undertaken in the last three years
2.       The bid bond (2% of the quoted fee) must be in form of bank guarantee form a reputable bank or approved insurance company.
3.       Adequate equipment and key personnel for the specified types of works
4.       Sound financial standing and adequate access to bank credit line
5.       Litigation history of the company (both court and arbitration cases)
6.       Duly signed and stamped confidential business questionnaire
7.       A valid tax compliance certificate
 
Further, tenders from the following tenderers shall be treated as NON – RESPONSIVE and therefore subject to automatic disqualification.
1.       A  tender from a tenderer whose on – going projects is/are behind schedule and without any approved extension of time.
2.       A tender from a tenderer who has been served with a default notice on – going projects or terminated in previous projects
3.       A tender from a tenderer with on-going projects exceeding four (4) in number, regardless of the total value of the outstanding works.
 
Tenders in plain sealed envelopes, marked tender number on the right hand side corner and bearing no indication of the tenderer should be addressed to:-

The Managing Director
Kenya Industrial Estates Limited
P. O. Box 78029 – 00507
NAIROBI
 
And placed in the tender box located on the Ground floor, KIE building, Likoni / Lusingeti Road, Industrial Area, Nairobi or sent by post so as to reach the above not later than the dates provided above at 10. 00 am respectively.
 
Only submitted TECHNICAL BIDS  will be opened publicly in the exhibition hall, behind the main building, soon after the above stated closing date and time in the presence of tenderers or their representatives who choose to attend.  Late bids will be returned unopened.  Prices quoted must be inclusive of all government taxes and remain valid  during the  whole contract period.
 
The bid security which must be from an established bank  or approved Insurance Company shall be valid for one hundred and twenty (120) days form the tender opening date.
 
Kenya Industrial Estates reserves the right to accept or reject a tender in whole of part without giving reasons for rejection and does not bind itself to accept the lowest or any tender.
 
MANAGING DIRECTOR